好色先生TV

Non-lawyers often raise the most compelling legal questions. One such question concerned the enforceability of so-called time bar clauses. Readers will be aware that when such clauses are upheld they can provide a complete defence to what otherwise would be a good claim for additional time and/or money. Naturally, contractors in such cases feel the employer has received a 鈥渨indfall鈥� in circumstances where there was no actual prejudice to the employer caused by the late notification. Phases such as 鈥渢echnical defence鈥�, 鈥渦nfair鈥�, and 鈥渃onstructive awareness of the delay鈥� are also commonplace.

What the non-lawyer wanted to know was whether these clauses were enforceable under English law and, in particular, why two cases appeared to provide two different answers. She queried the point of having such clauses in contracts if they were not widely understood or consistently operated. The two cases she wanted to query were the Privy Council case of NH International (Caribbean) Ltd vs National Insurance Property Development Company Ltd (Trinidad and Tobago) [2015] and the first instance case of Commercial Management (Investments) Ltd vs Mitchell Design and Construct Ltd & Anor [2016] in the Technology and Construction Court.

In the latter case, the court held that the following notice provision was unreasonable pursuant to the Unfair Contract Terms Act 1977: 鈥淎ll claims under or in connection with this Contract must in order to be considered as valid be notified to us in writing within 28 days of the appearance of any alleged defect or of the occurrence (or non-occurrence as the case may be) of the event complained of, and shall in any event be deemed to be waived and absolutely barred unless so notified within one calendar year of the date of completion of the works.鈥�

Contractors feel the employer has received a 鈥榳indfall鈥� in circumstances where there was no actual prejudice to the employer caused by the late notification

This was because the court found that the person required to give notice was not using the building and it was impractical to assume that he could be in a position to give notice within 28 days of the appearance of a defect. Would the position be different if the Unfair Contract Terms Act did not apply, she asked.

In the NH International case, the court was asked to look at notices to be given by an employer and whether clause 2.5 of the FIDIC forms of contract was a strict time bar. This clause sets out that if the employer 鈥渃onsiders itself to be entitled to any payment under any Clause of these Conditions or otherwise in connection with the Contract鈥�, it should, subject to certain specified exceptions give notice and particulars to the contractor. The clause says the 鈥渘otice shall be given as soon as practicable after the Employer became aware of the event or circumstances giving rise to the claim鈥�.

She asked, should clause 2.5 be construed as a time bar provision against the employer? Unlike the much discussed clause 20.1 of FIDIC (dealing with contractors鈥� claims), there is no specific time period stated in clause 2.5 and no clear words that an employer鈥檚 failure to notify will prevent him recovering damages from the contractor.

This appears to be in contrast with Bremer Handelgesellschaft mbH v Vanden Avenne Izegem PVBA [1978] 2 Lloyd鈥檚 Rep 109, where the House of Lords set out ingredients of an effective time bar 鈥� such a clause had to contain a precise time frame for notice to be served and include clear language that failure to notify within the prescribed time results in a party losing its rights.

Such a clause had to contain a precise time frame for notice to be served and include clear language that failure to notify within the prescribed time results in a party losing its rights

Well, the Privy Council held that clause 2.5 is an effective time-bar stating 鈥渋t is hard to see how the words of clause 2.5 could be clearer. Its purpose is to ensure that claims which an employer wishes to raise, 鈥� should not be allowed unless they have been the subject of a notice, which must have been given 鈥渁s soon as practicable鈥�.

If the employer could rely on claims which were first notified well after that, it is hard to see what the point of the first two parts of clause 2.5 was meant to be. Further, if an employer鈥檚 claim is allowed to be made late, there would not appear to be any method by which it could be determined, as the engineer鈥檚 function under FIDIC is linked to the particulars, which in turn must be contained in a notice, which in turn has to be served 鈥渁s soon as practicable鈥�.

My non-lawyer was perplexed and queried the implications of the Privy Council鈥檚 decision on other standard forms? For example, under the NEC3, clause 25.3 if the project manager decides that work does not meet the conditions for a key date and the employer incurs additional costs to meet this shortfall, the employer is entitled to recover the additional cost as assessed by the project manager within four weeks when the condition for the key date is fulfilled. If the employer does not provide the project manager with the details of the cost incurred for the project manager to reach an assessment within the four weeks period, does this mean the Employer is time barred based on NH International?

This is an elegant question but can one really give a straightforward binary answer?

Hamish Lal is a partner in the international arbitration practice at Akin Gump