A Part 8 application in relation to an adjudicator鈥檚 decision on an extension of time took a novel approach 

Tony bingham 2017 bw web

It a was brilliant idea; it just didn鈥檛 work. Brilliant all the same. It was an attempt to take the adjudicator鈥檚 decisions on appeal. ISG Construction Ltd was awarded a 拢29m design and build office block in Lombard Street, London EC3. The design, supply and installation of the unitised curtain walling and stone cladding was subcontracted to English Architectural Glazing Ltd (EAG). Its contract said it would commence works on site on 20 March 2017 and finish on 11 September 2017. By coincidence the finish date became the eventual start date, and over a year later the subcontract was all but done. A highly promising circumstance for a dispute 鈥 and indeed, ISG said that EAG was not entitled to all that extension of time, and claimed 拢3,183,000 compensation. Big money.

The adjudicator barrister, Mr Peter Collie, is highly experienced in such matters. Far from awarding 拢3m-plus to ISG, he awarded 拢137,434.00 to EAG. ISG paid up; not with a smile, however. Its lawyer picked over the adjudicator鈥檚 award, and brought what I call an appeal. ISG issued something called a Part 8 application in the High Court in Manchester before Judge Stephen Davies. It was not challenging the enforcement of the adjudicator鈥檚 decisions; it had already paid up. Rather it was seeking announcements or declarations from the judge that certain parts of the decisions were wrong and also wanted to know from the judge the 鈥渁mbit and effect鈥 of certain decisions. Why? So that ISG could decide whether, and if so on what basis, it could seek to enforce its claim for loss and damage in any further adjudications. That seems some distance from where we began with adjudication 20 years ago. 

ISG could simply begin afresh in court with the same dispute, but this time litigate

In a beguiling opening statement by the barrister for ISG, he explained that the court should be particularly willing to make announcements as to the ambit (scope) and effect of a first adjudicator鈥檚 decision in advance of any further adjudications because 鈥渢he reality is that disputes like this are almost always adjudicated as opposed to litigated or arbitrated, notwithstanding that in theory it is always open to a losing party in adjudication to have a dispute finally settled by the court or arbitrator鈥.

Now then, adjudicators鈥 decisions are binding until finally determined afresh by legal proceedings or by arbitration. In other words, ISG could simply begin afresh in court with the same dispute, but this time litigate. Witnesses are cross-examined, experts scrutinised in the witness box. Barristers argue the toss in depth. Believe me, it is drilling down to enormous depths compared with the high-speed rummaging in lever-arch files in adjudication. But here the idea of ISG鈥檚 lawyers was not only to pick out issues thought wrongly decided but also to ask the court to fathom the effect of this adjudication on future adjudicators.

Legal 2 main image

This device called Part 8 triggers a discretionary power available to the court. It can give 鈥渞elief鈥 in the interests of justice and do so without a full trial, without having to consider facts via witnesses etc. A typical Part 8 application is where the respondent argues the adjudicator had 鈥渘o jurisdiction鈥 to adjudicate, or else might raise the issue of whether a previous adjudication binds in another adjudication or 鈥 most commonly 鈥 whether the decision of the adjudicator is enforceable. ISG here admitted the adjudication decision was enforceable but came to court for crystal ball answers.

The key issue in the ISG vs EAG dispute in court was about the extension of time decision by the adjudicator. He had given an extension of time (EOT), but ISG came to court saying he was wrong, and it should have been zero EOT. It must be right to be able to challenge that important decision on EOT; it has important knock-on effects. The Part 8 challenge was a technical one: that the contractual notices machinery for EOT, being warning letters, had not been complied with. ISG argue that no evidence was needed because no notices were given, which would form a knock-out answer to EOT. In that case, a claim by ISG for compensation would be good. 

Scrutinising the words used in the decision to forecast impact on future disputes is unfair on the adjudicator

Wrong. The issue of EOT notices was a mixed question of fact and law: and thus inherently unsuitable for determination in isolation under Part 8. In other words, it requires a trial on the topic of whether proper notices were given.

As to the notion of ambit and effect or the consequences of the adjudicator鈥檚 answers, this was also a no-go. The court said it was only concerned with the question as to what was referred, and the question of what was decided. The idea of scrutinising the words used in the decision to forecast impact on future disputes is unfair on the adjudicator, given the pressure of time under which he, like all adjudicators, had to operate. Reasons given in the decision need not be exhaustive; they are only required to be brief. And, said the judge, 鈥渢his is not an appeal of process on the adjudicator鈥. Let me remind you, adjudication is not a trial, not a deep forensic investigation as happens in court. It is only a 鈥渞ough and ready鈥 decision as to who best shall hold the money in a typical construction industry dispute 鈥 precisely what ISG vs EAG was.

Tony Bingham is a barrister and arbitrator at 3 Paper 好色先生TVs, Temple

Topics