好色先生TV

The article 鈥淭ime is money鈥� by James Bessey, published in 好色先生TV on 17 May, discussed the recent decision of Carillion vs Emcor and Aecom. In particular, the article discussed the extent to which Emcor鈥檚 entitlement as a subcontractor to claim extensions of time had been affected by a supplemental agreement between Carillion and its employer, Rolls Development UK Limited.

The fact that the dispute arose from building works at the Rolls 好色先生TV, the home of the Technology and Construction Court, gives this case added resonance. 

This is yet another example of a dispute between a subcontractor and its main contractor.  The relationship between a main contractor and its client will often comprise claims and counterclaims, which will include the main contractor鈥檚 final account. This usually precedes the payment to the main contractor of a specific sum of money. The main contractor will then have to resolve its own liabilities with its subcontractors. Formerly, main contractors were often able to defer and delay settlement of their subcontractors鈥� accounts until they were able to secure settlement with their developer client. This preserved the main contractor鈥檚 cash flow. More recently, its ability to do so has, of course, been prejudiced by subcontractors鈥� abilities to pursue their claims through adjudication. 

Subcontractors will retain an interest in knowing the terms of any settlement concluded with its main contractor

Nonetheless, subcontractors will retain an interest in knowing the terms of any settlement concluded with its main contractor. If elements of the main contractor鈥檚 account which relates to their own work can be identified, this will be a useful negotiating tool. A subcontractor could identify a generous recovery for this element of the work for which it seeks a share. Similarly, if the correspondence between the main contractor and its subcontractor alleges failures and culpable performance by the subcontractor, to find that the correspondence between the main contractor and the developer states the contrary is perceived as being of great benefit.

The disclosure of this correspondence will be sought by a subcontractor as part of the usual disclosure process in any litigation. A main contractor may be unable to avoid disclosure of its everyday correspondence exchanges with its client but may have more success in withholding disclosure of any settlement agreement of its account or exchanges leading to this agreement. 

One cannot argue with the public policy considerations behind this judgment.  However, there may be suspicion that a main contractor has achieved an unduly favourable settlement

Whereas, on the one hand, it may be willing to disclose the documents evidencing settlement if it reflects an acknowledgement of  the subcontractor鈥檚 failures, if the opposite were true it may wish to withhold disclosure. But can the main contractor do this? This was an issue which came before the House of Lords in Rush & Tompkins Limited vs Greater London Council and others [1988]. Although this decision was made nearly three decades ago, it remains good law and its findings are directly applicable to such a situation. Rush & Tompkins had compromised its claims against the Greater London Council (GLC) for the sum of 拢1.2m in settlement of all its claims. Whereas the terms of this settlement were disclosed to its subcontractor, Carey, they did not show how much of the 拢1.2m, if anything, was included for Carey鈥檚 claim. 

As part of the litigation, Carey sought specific discovery of without prejudice correspondence between the parties leading to the settlement. It hoped that by the disclosure of these documents it would discover what was the value which the GLC had attributed to Carey鈥檚 works and the amount which the GLC had evaluated as representing Carey鈥檚 claim. Rush & Tompkins refused by stating that this correspondence was privileged from disclosure because it was conducted on a without prejudice basis for the purpose of settling its claim with the GLC. In the leading judgment given by Lord Griffiths, he thought that the wiser course was to protect without prejudice communications between parties to litigation from production to any other parties in the same litigation. He thought that it would otherwise be a discouragement to settlement. 

A party would be reluctant to settle if he believed that the admissions might subsequently be held against him. A main contractor would be discouraged if he thought that in achieving a settlement any admissions made by him could then be used against him by any other subcontractor with whom he might also be in dispute. It could even lead to situations where nothing would be put on paper in situations where, in conducting difficult negotiations, they were far better spelt out with precision in writing.

One cannot argue with the public policy considerations that sit behind this judgment.  However, there may be suspicion that a main contractor has achieved an unduly favourable settlement which could be at the subcontractor鈥檚 expense. In such circumstances the subcontractor should always look to the terms of his subcontract to see whether the GLC case may be distinguished, allowing them to peep behind the veil of privilege.

Jeffrey Brown is a partner in the London office of Veale Wasbrough Vizards